Skip navigation

Construction Services for Washroom Building at Newton Athletic Park






Construction Services for Washroom Building at Newton Athletic Park


Request for Expressions of Interest and Statements of Qualifications

Pre-Qualification of Building Contractor
This RFEOI/SOQ is intended to establish a list of building contractors with the necessary relevant expertise, capability and resources to perform the work.  Only those contractors that prequalify will be eligible to submit a bid.  Information is only being requested at this time to identify qualified contractors and, therefore, pricing for this project is not required and not requested at this time.

The City of Surrey seeks a qualified contractor or qualified contractors for the purpose of performing construction services for the construction of a washroom building at Newton Athletic Park.  The successful contractor will be responsible for constructing a 67 sq.m, one-storey, CMU masonry washroom and tying in to electrical, water, storm and sanitary services brought to within 2m of the footprint. 

Work Schedule
Surrey Forces intend to have the service stub outs roughed in at the site by mid-May.  Construction for the washroom is expected to be awarded by May 9, 2014 with work being mobilized immediately thereafter.  It is expected this work should take 15 weeks with Substantial Completion on or before August 22, 2014.

RFEOI/SOQ Document for download: 
Construction Services for Washroom Building NAP (.pdf)
Schedule B - Form of Submission (.doc)

If the City determines that an amendment is required to this RFEOI/SOQ, the City’s Representative will issue a written addendum by posting it on the BC Bid Website at (the “BC Bid Website) and the City Website at (the “City Website”) that will form a part of this RFEOI/SOQ. It is the responsibility of Respondents to check the BC Bid Website and the City Website for addenda. The only way this RFEOI/SOQ may be added to, or amended in any way, is by a formal written addendum. No other communication, whether written or oral, from any person will affect or modify the terms of this RFEOI/SOQ or may be relied upon by any Respondent. By delivery of a Submission, a Respondent is deemed to have received, accepted and understood the entire RFEOI/SOQ, including any and all addenda.

All inquiries related to this RFEOI/SOQ should be directed in writing to the person named below.

Closing Date:

On or before April 22, 2014.


Richard Oppelt
Purchasing Manager
Tel: (604) 590-7274

Status: Shortlisted have been notified.







Business & Economic Development Menu