Skip navigation

Prequalification of General Contractor for Concrete Repairs and Painting of Two Only Sea Dams





Prequalification of General Contractor for Concrete Repairs and Painting of Two Only Sea Dams


Request for Expressions of Interest and Statement of Qualifications

The City of Surrey invites expressions of interest and statements of qualifications of general contractors for concrete repairs and painting of two only sea dams from qualified firms for the design and construction contract administration.

The City seeks a qualified Contractor or qualified Contractors for the purpose of performing services for concrete repairs and painting of the Nicomekl and Serpentine Sea Dams. The services may span multiple contracts over several years between 2015 and 2019.

RFEOI/SOQ Document for download: 
GC for Concrete Repairs and Painting of Two Only Sea Dams (.pdf)
Schedule B - Form of Submission (.doc)

If the City determines that an amendment is required to this RFEOI/SOQ, the City Representative will issue a written addendum by posting it on the BC Bid Website at (the “BC Bid Website”) and the City Website at (the “City Website”) that will form part of this RFEOI/SOQ. It is the responsibility of Respondents to check the BC Bid Website and the City Website for addenda. The only way this RFEOI/SOQ may be added to, or amended in any way, is by a formal written addendum. No other communication, whether written or oral, from any person will affect or modify the terms of this RFEOI/SOQ or may be relied upon by any Respondent. By delivery of a Submission, Respondent is deemed to have received, accepted and understood the entire RFEOI/SOQ including, any and all addenda.

All inquiries related to this RFEOI/SOQ should be directed in writing to the person named below.

Closing Date:

Prefer to receive Submissions on or before April 20, 2015.


Richard Oppelt
Purchasing Manager
Finance & Technology Department
Tel: (604) 590-7274

Status: Shortlisted have been notified.













Business & Economic Development Menu